H.R. 3944IntroducedHouseSenatePresident · nowLawBecame law through another billSec. 120 · H.R. 3944
Untitled section
Division C — Legislative Branch Appropriations Act, 2026 › Title I — LEGISLATIVE BRANCH
Read this section in the full bill →
This section appears in one version only, so there is nothing to compare yet.
None of the funds made available in this Act for the Architect of the Capitol may be used to make incentive or award payments to contractors for work on contracts or programs for which the contractor is behind schedule or over budget, unless the Architect of the Capitol, or agency-employed designee, determines that any such deviations are due to unforeseeable events, government-driven scope changes, or are not significant within the overall scope of the project and/or program.