Untitled section
Division D — Military Construction, Veterans Affairs, and Related Agencies Appropriations Act, 2026 › Title II
Read this section in the full bill →
No wording changed between Senate changes and Final version sent to the President.
How the text changed
None of the funds appropriated or otherwise made available by this Act may be used to pay award or incentive fees for contractors whose performance has been judged to be below satisfactory, behind schedule, over budget, or has failed to meet the basic requirements of a contract, unless the Agency determines that any such deviations are due to unforeseeable events, government-driven scope changes, or are not significant within the overall scope of the project and/or program and unless such awards or incentive fees are consistent with section 16.401(e)(2) of the Federal Acquisition Regulation.
None of the funds appropriated or otherwise made available by this Act may be used to pay award or incentive fees for contractors whose performance has been judged to be below satisfactory, behind schedule, over budget, or has failed to meet the basic requirements of a contract, unless the Agency determines that any such deviations are due to unforeseeable events, government-driven scope changes, or are not significant within the overall scope of the project and/or program and unless such awards or incentive fees are consistent with section 16.401(e)(2) of the Federal Acquisition Regulation.
added wordsremoved wordsComparison computed by Public Law Tracker from the official text