Early access: 15,549 bills from the current Congress so far, more added daily. Data from Congress.gov, GovInfo and the House and Senate vote records, updated Oct 13, 2026.
Public Law TrackerPLTPublic Law Tracker
H.R. 7148IntroducedHouseSenatePresidentLawBecame law
Sec. 416 · H.R. 7148

Untitled section

Division D — TRANSPORTATION, HOUSING AND URBAN DEVELOPMENT, AND RELATED AGENCIES APPROPRIATIONS ACT, 2026 › Title IV — GENERAL PROVISIONS—THIS ACT

Read this section in the full bill →

No wording changed between Introduced and Passed the House.

How the text changed

Before / AfterRedline
Introduced · Sec. 416

None of the funds appropriated or otherwise made available by this Act may be used to pay award or incentive fees for contractors whose performance has been judged to be below satisfactory, behind schedule, over budget, or has failed to meet the basic requirements of a contract, unless the Agency determines that any such deviations are due to unforeseeable events, government-driven scope changes, or are not significant within the overall scope of the project and/or program unless such awards or incentive fees are consistent with 16.401(e)(2) of the Federal Acquisition Regulations.

•HR 7148 IHSEC. 416
Passed the House · Sec. 416

None of the funds appropriated or otherwise made available by this Act may be used to pay award or incentive fees for contractors whose performance has been judged to be below satisfactory, behind schedule, over budget, or has failed to meet the basic requirements of a contract, unless the Agency determines that any such deviations are due to unforeseeable events, government-driven scope changes, or are not significant within the overall scope of the project and/or program unless such awards or incentive fees are consistent with 16.401(e)(2) of the Federal Acquisition Regulations.

•HR 7148 EHSEC. 416

added wordsremoved wordsComparison computed by Public Law Tracker from the official text